Web Site Design Terms and Conditions Policy.
Back
Note. This is an example of our general SLA or web site design agreement and
would be modified to mutually suit the clients application or situation.
This Agreement is made online between the agreed client and SphereCreation.
SphereCreation at the address, of the (“Developer”) and the online agreed,
("Client”), and collectively referred to as the "Parties." Contract confirmation
is or has been made with the associated email.
WITNESSETH
Whereas, Developer is in the business of offering Internet services relating to
development of sites on the World Wide Web portion of the Internet, and is
willing to provide services to Client on the terms and subject to the conditions
set forth below; and:
Whereas Client desires to engage Developer, and Developer desires to be engaged
by Client, to provide Internet services on the terms and subject to the
conditions set forth below.
Now, therefore, the Parties hereby agree as follows.
1. Developer Services
Developer agrees to provide Client with services for development of a Web site
on the World Wide Web portion of the Internet (the “Web Site") as set forth or
described in Exhibit B hereto (the “Web Site Specifications") and to provide
Client with additional services, if any, set forth or described in Schedule 3
hereto and mutually agreed upon in writing by the Parties (the "Additional
Services'). The obligations of Developer, if any, to provide ongoing maintenance
tasks for the Web Site shall be set forth and included as part of Additional
Services on Schedule 4 hereto ("Maintenance”).The Web Site Services and the
Additional Services are hereinafter referred to collectively as the "Services".
Client agrees that Developer is responsible only for providing the Services, and
Developer is not responsible for providing any services or performing any tasks
not specifically set forth in Exhibit B or Schedule 3 hereto.
2. Web Site Development and Transfer
2.1 Specifications and Client Content
Developer, in consultation with Client, shall prepare detailed written
specifications for the Web Site (the "Specifications"). The Specifications shall
consist of, among other things, a design for the Web Site, a flow-chart of the
pages for the Web Site, programming and interactive feature requirements, and
the placement of any content or other materials which are to be incorporated
into the Web Site. The Specifications shall be subject to any restrictions or
limitations set forth in Exhibit B or Schedule 3. The Specifications which have
been mutually agreed upon by the Parties in writing shall be attached hereto as
Exhibit B and 3. If the Parties are unable to agree in writing to mutually
acceptable Specifications, after using good faith efforts, on or before days
after the Commencement Date, either party may terminate this Agreement by
providing written notice to the other party. Such termination shall not relieve
Client from the obligation of paying Developer for all fees due and owing
Developer as of the date of such termination.
2.2 Delivery of Client Content
"Client Content” shall mean any materials provided by Client for incorporation
in the Web Site, including, but not limited to, any images, photographs,
illustrations, graphics, audio clips, video clips or text. Client shall deliver
the Client Content to Developer in an electronic file format specified and
accessible by Developer (eg, txt, gif) or as otherwise specified in the
Specifications. Any services required to convert or input Client Content not set
forth in the Specifications shall be charged as Additional Services. Client
shall promptly deliver all Client Content to Developer as required by Developer.
2.3 Initial Version
Upon completion of mutually agreeable Specifications, and upon Developer's
receipt of the Client Content and any fees called for in Exhibit A hereto,
Developer shall commence tasks associated with the development of the initial
version of the Web Site ("Initial Version”) and notify the Client of the URL
(Uniform Resource Locator) or other address of the Initial Version. Developer
shall use combinations of technology as Developer, in consultation with the
Client, deems appropriate to develop the Web Site.
2.4 Revisions
Client shall have 14 days, or such time as otherwise agreed by the Parties in
writing, from the date of a written notice of completion of the Initial Version
from Developer to review and request in writing from Developer revisions to the
Initial Version. Upon receipt of such requests, Developer shall use commercially
reasonable efforts to implement such revision requests that are within the scope
of, and consistent with, the Specifications. If Client wishes to implement any
revisions to the Web Site that deviate in any material respect from the
Specifications, Client shall submit to Developer a written change order
containing (i) such revisions in detail and (ii) a request for a price quote for
each change (collectively, the "Change Order). Developer shall promptly evaluate
the Change Order and submit to Client for its written acceptance a proposal for
undertaking the applicable tasks and a price quote reflecting all associated
fees associated with Client's Change Order. Client shall have 14 business days
from receipt of such proposal to accept or reject Developer's proposal in
writing. If Client accepts Developer's proposal to undertake the work
necessitated by the Change Order, then the Change Order, as supplemented and/or
modified by Developer's proposal, shall amend and become a part of the
Specifications in Exhibit B and Schedule 3 as appropriate and Exhibit A hereto
(Fee and Payment Schedule), and Developer shall proceed to implement such
revisions in accordance with the Specifications and Exhibit B and Schedule 3 as
so modified. If (i) Client has not made any requests for revisions by the end of
14 days from the date of written notice of completion of the Initial Version
from Developer, or by such time as otherwise agreed by the Parties in writing,
or (ii) upon completion of implementation of such requests which were mutually
agreed upon by the Parties under the revised Specifications, the Web Site shall
be deemed accepted by Client ("Acceptance”).
2.5 Transfer
Upon Acceptance of the Web Site and payment of all fees called for in Exhibit A
hereto, Developer shall transfer the Web Site to the computer system owned and
operated by Client and/or its designated third party contractor, identified on
Exhibit B hereto, through which the Web Site may be accessed via the World Wide
Web portion of the Internet (the "Host Server).
2.6 Work Order Forms
Subsequent to the execution of this Agreement by the Parties, in the event
Developer and Client agree that Developer is to perform additional tasks not in
the original scope of Services hereunder, then the Parties shall execute a work
order form (each an "Order Form) in the form attached hereto as Schedule 5, upon
which each such Schedule 5 shall be incorporated into and shall become a part of
this Agreement and shall be subject to the terms and conditions hereof.
3. Proprietary Rights
3.1 Proprietary Rights of Client
As between Client and Developer, Client Content shall remain the sole and
exclusive property of Client, including, without limitation, all copyrights,
trademarks, patents, trade secrets, and any other proprietary rights. Nothing in
this Agreement shall be construed to grant Developer any ownership right in, or
license to, the Client Content, except as provided in Section 3.2 of this
Agreement.
3.2 Proprietary Rights of Developer
Subject to Client's ownership interest in Client Content, all materials,
including, but not limited, to any computer software (in object code and source
code form), script, programming code, data, information or HTML script developed
or provided by Developer or its suppliers under this Agreement (with the
exception of original elements of audio visual displays created hereunder
specifically for Client, which shall be deemed to be part of Client Content),
and any trade secrets, know-how, methodologies and processes related to
Developer's products or services, shall remain the sole and exclusive property
of Developer or its suppliers, including, without limitation, all copyrights,
trademarks, patents, database rights, trade secrets, and any other proprietary
rights inherent therein and appurtenant thereto (collectively "Developer
Materials'). To the extent, if any, that ownership of the Developer Materials
does not automatically vest in Developer by virtue of this Agreement or
otherwise, Client hereby transfers and assigns to Developer all rights, title
and interest which Client may have in and to the Developer Materials. Client
acknowledges and agrees that Developer is in the business of designing and
hosting Web sites, and that Developer shall have the right to provide to third
parties services which are the same or similar to the Services, and to use or
otherwise exploit any Developer Materials in providing such services. The
Develop has sole rights to host and develop this site and remains the sole
Webmaster for at least the period of two years from the initial contract date.
3.3 Confidentiality
Each party agrees that during the course of this Agreement, information that is
confidential or proprietary may be disclosed to the other party, including, but
not limited to software, technical processes and formulas, source codes, product
designs, sales, cost and other unpublished financial information, product and
business plans, advertising revenues, usage rates, advertising relationships,
projections, and marketing data ("Confidential Information"). Confidential
Information shall not include information that the receiving party can
demonstrate (a) is, as of the time of its disclosure, or thereafter becomes part
of the public domain through a source other than the receiving party, (b) was
known to the receiving party as of the time of its disclosure, (C) is
independently developed by the receiving party, or (d) is subsequently learned
from a third party not under a confidentiality obligation to the providing
party. Except as provided for in this Agreement, each party shall not make any
disclosure of the Confidential Information to anyone other than its employees
who have a need to know in connection with this Agreement. Each party shall
notify its employees of their confidentiality obligations with respect to the
Confidential Information and shall require its employees to comply with these
obligations. The confidentiality obligations of each party and its employees
shall survive the expiration or termination of this Agreement.
3.4 Developer Notices
Unless otherwise agreed to in writing by the Parties, Developer shall have the
right to place proprietary notices of Developer and its suppliers (including
hypertext links related thereto) on the Developer Materials and on the Web Site,
including developer attribution and hypertext links to Developers web sites, and
to change or update such notices from time to time upon notice to Client. In no
event may client remove or alter any Developer proprietary notice from the
Developer Materials or the Web Site without Developers prior written consent.
3.5 Developer Copyright
Unless otherwise agreed to in writing by the Parties, the Developer retains the
Copyright for the developed web site. Any variation to this agreement needs to
be agreed in advanced before the web site is developed.
4. License
4.1 Grant of License - Client
Client hereby grants to Developer a non-exclusive, world wide, royalty-free
license to edit, modify, adapt, translate, Schedule, publish, transmit,
participate in the transfer of, reproduce, create derivative works from,
distribute, perform, display, and otherwise use Client Content as necessary to
render the Services to Client under this Agreement.
4.2 Grant of License - Developer
Developer hereby grants to Client a limited, non-exclusive, non-transferable
license solely to make use of Developer Materials which are incorporated in the
Web Site and which are required for the operation of the Web Site solely to
operate the Web Site on the Host Server. Developer hereby reserves for itself
all rights in and to the Developer Materials not expressly granted to Client in
the immediately foregoing sentence. In no event shall Client use any trademarks
or service marks of Developer without Developer's prior written consent. Unless
otherwise agreed to in writing by Developer, the transfer or attempted transfer
of the Web Site to any host server other than the Host Server shall
automatically terminate the foregoing license.
5. Client Content
5.1 Accuracy and Review of Client Content
Client assumes sole responsibility for: (a) acquiring any authorization(s)
necessary for hypertext links to third party Web sites; and (b) the accuracy of
materials provided to Developer, including, without limitation, Client Content,
descriptive claims, warranties, guarantees, nature of business, and address
where business is conducted; and (c) ensuring that the Client Content does not
infringe or violate any right of any third party, including without limitation,
intellectual property rights and without violating any law.
5.2 Limitations on Client Content
Client shall provide Client Content that does not contain any content or
materials which are obscene, threatening, malicious, which infringe on or
violate any applicable law or regulation or any proprietary, contract, moral,
privacy or other third party right, or which otherwise expose Developer to civil
or criminal liability. Any such materials provided by Client to Developer which
do not satisfy the foregoing requirements in this Section 5.2 shall be deemed to
be a material breach of this Agreement.
6. Fees and Taxes
6.1 Web Site Services Fees
In consideration for that portion of the Services to be rendered by Developer in
connection with developing and finalizing the Specifications, Client shall pay
to Developer, upon execution of this Agreement, the fees identified in Exhibit A
hereto under the heading "Specification Fees" (the "Specification Fees') unless
otherwise agreed and set out in Exhibit A. Upon Acceptance of the Specifications
by Client, Developer and Client shall negotiate in good faith to agree on fees
to be paid by Client for the balance of the Services. Such agreed-upon fees and
associated payment schedules shall then be inserted on Exhibit A hereto under
the heading "Non-Specification Fees" (the "Non-Specification Fees'), and
initialed and dated by authorised representatives of each of the Parties. Client
shall pay the Non-Specification Fees in accordance with the applicable payment
schedule set forth in Exhibit A hereto, provided that Developer expressly
reserves the right to change the rates charged hereunder for the Services during
any Renewal Term. In the-event Developer and Client are unable to agree on
Non-Specification Fees following completion of the Specifications and after
negotiating in good faith, either Party may terminate this Agreement upon days
prior written notice to the other Party.
6.2 Web Masters Maintenance Fees
As part of the standard Web Masters agreement, the client agrees to pay
SphereCreation, the Developer, an annual Web Masters Fee. Unless otherwise
agreed, this fee is £50 (pounds)/year. As agreed, the Developer will then
maintain the clients web site content, such as, the online copyright
notification, privacy policy and email, (mail box) set-up on a monthly basis.
Thereafter, further changes in content or HTML tags would constitute additional
development and therefore would incur additional costs to the client under the
agreed schedule.
6.3 Other Maintenance Fees
To the extent that Developer is to provide additional Maintenance under Schedule
4 hereto, Client shall pay for all Maintenance-related tasks on a time and
materials basis, as invoiced by Developer, unless otherwise expressly provided
on Exhibit A hereto for a period of at least two years from the initial contract
date. Web starter Entry Package.
6.4 Out-of-Pocket Expenses
Client shall pay, or promptly reimburse Developer for, any out-of-pocket
expenses, including, without limitation, travel and travel-related expenses,
incurred by Developer in connection with the performance of the Services.
6.5 Additional Services Fees
Unless otherwise agreed by the Parties in writing on Schedule 3 hereto, Client
shall pay to Developer all fees for Additional Services on a time and materials
basis as invoiced by Developer.
6.6 Late Payment
Client shall pay to Developer all fees not specifically itemised on Exhibit A
within 30 days of the date of the applicable Developer invoice. If Client fails
to pay any fees within 7-10 days from the date due according to Exhibit A, or
within 30 days from the date of an invoice, where applicable, then (without
prejudice to the Developer’s other rights and remedies) the Developer reserves
the right to charge interest on such sum on a day to day basis (as well after as
before any judgment) from the date or last date for payment thereof to the date
of actual payment (both dates inclusive) at the rate of 2 per cent above the
base rate of Royal Bank of Scotland plc (or such other London Clearing Bank as
the Developer may nominate) from time to time in force compounded quarterly.
Such interest shall be paid on demand by the Developer.
In addition, failure of Client to fully pay any fees within 30 days after the
applicable due date shall be deemed a material breach of this Agreement
justifying suspension of the performance of the Services by Developer, and will
be sufficient cause for immediate termination of this Agreement by Developer.
The Developer may withdraw the Web Site from the World Wide Web (if hosted by or
on behalf of the Developer) forthwith in this event. Any such suspension does
not relieve Client from paying past-due fees plus interest. Client shall be
liable for any costs associated with such fee recovery, including, but not
limited to, legal costs, court costs, and collection agency fees.
6.7 Taxes
Client shall pay or reimburse Developer for all sales, use, transfer, privilege,
excise, value added tax and all other taxes and all duties, whether
international, national, state or local, however designated, which are levied or
imposed by reason of the performance by Developer under this Agreement;
excluding, however, income taxes on profits which may be levied against
Developer.
7. Warranties
7.1 Developer Warranties
Developer represents and warrants that (a) Developer has the power and authority
to enter into and perform its obligations under this Agreement, and (b)
Developer's Services under this Agreement shall be performed with reasonable
skill and care. Developer further warrants to Client that, to the best of
Developer's knowledge, the Developer Materials do not and will not infringe, or
be misappropriations of, the property rights of third parties, provided,
however, that Developer shall not be deemed to have breached such warranty to
the extent that Client or its agent(s) have modified the Web Site in any manner
or if the Web Site incorporates unauthorised third-party materials, through
framing or otherwise. (c) the Web Site will conform to the Specifications. If
the Web Site does not conform to the Specifications, Developers shall be
responsible to correct the Web Site without unreasonable delay, at Developers
sole expense and without charge to Client, to bring the Web Site into
conformance with the Specifications. Client waives any other warranty, express
or implied. Client acknowledges that Developers do not warrant that the Web Site
will work on all platforms. Client acknowledges that Developers are not
responsible for the results obtained by the Client on the Web Site.
7.2 Client Warranties
Client represents and warrants that (a) Client has the power and au-thority to
enter into and perform its obligations under this Agreement, (b) Client Content
does not and shall not contain any content materials, advertising or services
that are inaccurate or that infringe on or violate any applicable law,
regulation or right of a third party, including, without limitation, export
laws, or any proprietary, contract, moral, or privacy right or any other third
party right, and that Client owns the Client Content or otherwise has the right
to place the Client Content on the Web Site, and (c) Client has obtained any
authorization(s) necessary for hypertext links from the Web Site to other third
party Web sites.
7.3 Disclaimer of Warranty
Except for the limited warranties set forth in Section 7. 1, developer makes no
warranties hereunder and developer expressly disclaims all other warranties,
express or implied, including, without limitation, warranties of merchantability
and fitness for a particular purpose.
8. Indemnification
8.1 Client
Client agrees to indemnify, defend, and hold harmless Developer, its directors,
officers, employees and agents, and defend any action brought against same with
respect to any claim, demand, cause of action, debt or liability, including
reasonable legal fees, to the extent that such action is based upon a claim
that: (i) if true, would constitute a breach of any of Client's representations,
warranties, or agreements hereunder; (ii) arises out of the negligence or wilful
misconduct of Client; or (iii) any of the Client Content to be provided by
Client hereunder or other material on the Web Site infringes or violates any
rights of third parties, including, without limitation, rights of publicity,
rights of privacy, patents, copyrights, trademarks, database rights, trade
secrets and/or licenses.
8.2 Notice
In claiming any indemnification hereunder, the Developer shall promptly provide
the Client with written notice of any claim which the Developer believes falls
within the scope of the foregoing paragraph. Client may, at its own expense,
assist in the defense if it so chooses, provided that the Developer shall
control such defense and all negotiations relative to the settlement of any such
claim and further provided that any settlement intended to bind the Developer
shall not be final without the Developer’s written consent, which shall not be
unreasonably withheld.
9. Limitation of Liability
(1) The Developer shall indemnify the Client and keep the Client fully and
effectively indemnified on demand against any loss of or damage to any property
or injury to or death of any person caused by any negligent act or omission or
wilful misconduct of the Developer, its employees, agents or sub-contractors or
by any defect in the design or workmanship or supply of the Web Site Services.
(2) The Client shall indemnify the Developer and keep the Developer fully and
effectively indemnified on demand against any loss of or damage to any property
or injury to or death of any person caused by any negligent act or omission or
wilful misconduct of the Client, its employees, agents or sub-contractors.
(3) Except in respect of injury to or death of any person (for which no limit
applies) the respective liability of the Developer and the Client under
sub-clauses (1) and (2) in respect of each event or series of connected events
shall not exceed the total value of fees payable pursuant to Exhibit A for the
services to be supplied if the contract was performed in full.
(4) Notwithstanding anything else contained in this Agreement the Developer
shall not be liable to the Client for loss of profits or contracts or other
indirect or consequential loss whether arising from negligence, breach of
contract or howsoever.
(5) The Developer shall not be liable to the Client for any loss arising out of
any failure by the Client to keep full and up-to-date security copies of the Web
Site computer programs and data it uses in accordance with best computing
practice. Neither will the Developer be liable for any delay in delivery of the
Web Site to the Host Server howsoever such delay may be caused.
10. Termination
10.1 Term
This Agreement shall be commenced when signed by the Parties and thereafter
shall remain in Effect until the Developer delivers to the Client an operational
Web site in accordance with the Specifications in and milestones (if any) set
out in Exhibit B. Client acknowledges, however, that any delivery deadline, and
the other payment milestones listed in Exhibit B, are estimates, and are not
required delivery dates. In relation to these dates time shall not be of the
essence and the Client must make required payments as per Exhibit B in any
event. The Developer has sole rights to host and develop this site and remains
the sole Webmaster for at least the period of two years from the initial
contract date. This relationship is then automatically renewed as the hosting
contract continues and the domain name is reregistered.
10.2 Termination
(1) This Agreement may be terminated forthwith by either party on giving notice
in writing to the other if the other party shall have a receiver or
administrative receiver appointed or shall pass a resolution for winding-up
(otherwise than for the purpose of a bona fide scheme of solvent amalgamation or
reconstruction), or a court of competent jurisdiction shall make an order to
that effect or if the other party shall become subject to an administration
order or shall enter into any voluntary arrangement with its creditors or shall
cease or threaten to cease to carry on business, or in the case of an individual
shall be adjudicated bankrupt.
(2) Any termination under sub-clause (1) shall discharge the parties from any
liability for further performance of this Agreement and in the case of a
termination by the Developer shall entitle the Developer to enter any of the
Client’s premises and recover any equipment and materials the property of the
Developer (and so that the Client hereby irrevocably licenses the Developer, its
employees and agents to enter any such premises for that purpose) and also to be
paid a reasonable sum for any work carried out by it prior to such termination
and in the case of a termination by the Client shall entitle the Client to be
repaid forthwith any sums previously paid under this Agreement (whether paid by
way of a deposit or otherwise) and to recover from the Developer the amount of
any direct loss or damage sustained or incurred by the Client as a consequence
of such termination.
(3) Any termination of this Agreement (howsoever occasioned) shall not affect
any accrued rights or liabilities of either party nor shall it affect the coming
into force or the continuance in force of any provision hereof which is
expressly or by implication intended to come into or continue in force on or
after such termination.
(4) Any termination of this Agreement can not be completed within the first two
years of the contact unless specified or agreed with the Developer. This can
only be completed after the payment of any outstanding fees for the development
of any initial or promotional material, or after due consideration give to the
introductory offer on which this contract was agreed.
11. Designated Contact
Each party shall designate one person who will act as the primary liaison for
all communications regarding the Services to be rendered by Developer hereunder.
12. Waiver of Remedies
No forbearance, delay or indulgence by either party in enforcing the provisions
of this Agreement shall prejudice or restrict the rights of that party nor shall
any waiver of its rights operate as a waiver of any subsequent breach and no
right, power or remedy herein conferred upon or reserved for either party is
exclusive of any other right, power or remedy available to that party and each
such right, power or remedy shall be cumulative.
13. Entire Agreement
This Agreement supersedes all prior agreements, arrangements and understandings
between the parties and constitutes the entire agreement between the parties
relating to the subject matter hereof. No addition to or modification of any
provision of this Agreement shall be binding upon the parties unless made by a
written instrument signed by a duly authorised representative of each of the
parties.
14. Assignment
Save as expressly provided in this Agreement, neither party shall assign or
otherwise transfer this Agreement or any of its rights and obligations hereunder
whether in whole or in part without the prior written consent of the other.
15. Notices
All notices which are required to be given hereunder shall be in writing and
shall be sent to the address of the recipient set out in this Agreement or such
other address in England as the recipient may designate by notice given in
accordance with the provisions of this Clause. Any such notice may be delivered
personally or by first class pre-paid letter or facsimile transmission and shall
be deemed to have been served if by hand when delivered, if by first class post
48 hours after posting and if by facsimile transmission when despatched.
16. Interpretation
In this Agreement:
(1) words importing the singular include the plural, words importing any gender
include every gender and words importing persons include bodies corporate and
unincorporate; and (in each case) vice versa;
(2) any reference to a party to this Agreement includes a reference to his
successors in title and permitted assigns;
(3) the headings to the Clauses are for ease of reference only and shall not
affect the interpretation or construction of this Agreement.
17. Law
This Agreement shall be governed by and construed in accordance with the laws of
England.
18. Disputes
Any dispute which may arise between the parties concerning this Agreement shall
be determined by the English Courts and the parties hereby submit to the
exclusive jurisdiction of the English Courts for such purpose.
19. Severability
Notwithstanding that the whole or any part of any provision of this Agreement
may prove to be illegal or unenforceable the other provisions of this Agreement
and the remainder of the provision in question shall remain in full force and
effect.
20. Independent Contractors
Developer and its personnel, in performance of this Agreement, are acting as
independent contractors and not employees or agents of Client.
21. Amendments
No amendment, change, waiver, or discharge hereof shall be valid unless in
writing and signed by the party against which such amendment, change, waiver, or
discharge is sought to be enforced.
22. Client Identification
Developer may use the name of and identify Client as a Developer client, in
advertising, publicity, or similar materials distributed or displayed to
prospective clients.
23. Force Majeure
Except for the payment of fees by Client, if the performance of any part of this
agreement by either party is prevented, hindered, delayed or otherwise made
impracticable by reason of any flood, dot, fire, judicial or governmental
action, labour disputes, act of God or any other causes beyond the control of
either party, that party shall be excused from such to the extent that it is
prevented, hindered or delayed by such causes.
IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by
their duly authorised representatives on.
CLIENT: WEB DEVELOPER:
Name: (On-line) Notification & Agreement Name: Mr Developer
Date: On-line) Notification & Agreement Date: (On-line) Notification & Agreement
SCHEDULE 3
(Additional Services)
After the annual web hosting charges have been paid, the web site will be
maintained for a WEBMASTERS fee for a period of two years. At which time the
agreement can be reviewed on a rolling date basis.
SCHEDULE 4
(Maintenance)
Additional web site maintenance, such as web traffic booster services and the
updating of web pages will be agreed between the client and SphereCreation in
writing or email.
SCHEDULE 5
(Work Order form)
To be agreed with the developer at the appropriate time
Date: NA (mutually agreed)
Authorised by client: _____________________
Authorised by developer: __________________
Describe the project change request:
No changes to date.
Financial impact on project:
Delivery date change for project:
Additional notes:
Top
Back
